Subcontracting clause: Copy, customize, and use instantly
Introduction
A subcontracting clause outlines the conditions under which a party may subcontract part of its obligations under a contract. It clarifies when and how subcontracting is allowed, any restrictions on the use of subcontractors, and the responsibilities the primary party retains even when subcontractors are involved. This clause helps ensure that subcontracting does not compromise the quality or timelines of the work and that the primary party remains liable for subcontractor performance.
Below are templates for subcontracting clauses tailored to different scenarios. Copy, customize, and insert them into your agreement.
General subcontracting clause
This clause allows subcontracting with approval.
The contractor may subcontract any portion of the work under this Agreement, provided that the subcontractor is qualified and approved by the client. The contractor will remain fully responsible for the performance of the subcontracted work and will ensure that the subcontractor adheres to the terms of this Agreement.
Subcontracting clause with limitations
This clause allows subcontracting with limitations.
The contractor may subcontract parts of the work under this Agreement, but shall not subcontract the entirety of the project or any critical tasks without the prior written consent of the client. The contractor will remain liable for all obligations performed by any subcontractor.
Subcontracting clause with client approval
This clause requires client approval for subcontractors.
The contractor shall not engage any subcontractors to perform work under this Agreement without the prior written approval of the client. The client has the right to approve or reject any proposed subcontractors, and the contractor shall ensure that the subcontractor complies with the terms of this Agreement.
Subcontracting clause for compliance with contract terms
This clause ensures subcontractors comply with the agreement.
Any subcontractor engaged by the contractor must comply with all terms and conditions of this Agreement, including but not limited to timelines, performance standards, and confidentiality requirements. The contractor shall ensure that the subcontractor executes a separate agreement that mirrors these terms.
Subcontracting clause for accountability and liability
This clause makes the contractor accountable for subcontractor actions.
The contractor shall be fully responsible for the performance of any subcontractors. The contractor will indemnify the client against any claims, damages, or losses arising from the subcontractor’s actions or omissions, and shall ensure the subcontractor meets the performance and quality standards set forth in this Agreement.
Subcontracting clause for confidentiality and intellectual property
This clause ensures confidentiality and intellectual property protection.
The contractor will ensure that any subcontractor engaged under this Agreement signs a confidentiality agreement that protects the client’s intellectual property and sensitive information. The subcontractor shall not disclose or use such information for any purpose other than the completion of the work under this Agreement.
Subcontracting clause for payment terms with subcontractors
This clause defines payment terms for subcontractors.
The contractor shall be responsible for paying all subcontractors according to the terms set forth in the subcontractor’s agreement. The client shall not be liable for any payments owed to the subcontractor and shall pay the contractor in accordance with the agreed payment schedule under this Agreement.
Subcontracting clause for scope of work
This clause specifies the subcontractor’s scope of work.
The subcontractor shall only perform tasks that fall within the scope of work outlined in the subcontractor agreement, which must be consistent with the overall project goals and deliverables. The contractor is responsible for ensuring that the subcontractor’s work aligns with the terms of this Agreement.
Subcontracting clause for subcontractor qualifications
This clause ensures subcontractor qualifications.
The contractor must ensure that any subcontractor hired under this Agreement is fully qualified to perform the work required, including having the necessary licenses, certifications, and experience. The contractor is responsible for vetting the subcontractor and ensuring they meet all applicable standards.
Subcontracting clause for subcontractor performance monitoring
This clause defines how subcontractor performance will be monitored.
The contractor will monitor the performance of any subcontractor engaged under this Agreement to ensure compliance with all terms, timelines, and quality standards. The contractor shall provide the client with regular updates on the subcontractor’s progress and performance.
Subcontracting clause for subcontractor’s compliance with regulations
This clause ensures compliance with relevant regulations.
The subcontractor shall comply with all applicable laws, regulations, and industry standards while performing work under this Agreement. This includes complying with health and safety regulations, environmental standards, and any other legal obligations related to the performance of the work.
Subcontracting clause for subcontractor’s responsibilities in case of default
This clause defines subcontractor responsibilities in case of default.
In the event that the subcontractor defaults or fails to perform its obligations, the contractor shall take immediate action to remedy the situation. The contractor will remain fully responsible for ensuring the completion of the work, either by remedying the default or by hiring an alternative subcontractor to fulfill the obligations.
Subcontracting clause for subcontractor’s right to assign work
This clause limits the subcontractor’s right to assign work.
The subcontractor shall not assign, transfer, or subcontract any portion of the work to another party without the prior written consent of the contractor. Any unauthorized assignment will be deemed a breach of this Agreement.
Subcontracting clause for subcontractor’s duty to cooperate with the client
This clause ensures subcontractor cooperation with the client.
The subcontractor agrees to cooperate fully with the client, including providing access to information, personnel, or resources needed to complete the work. The subcontractor will work with the client’s team to ensure the successful completion of the work according to the project schedule.
Subcontracting clause for subcontractor’s dispute resolution
This clause specifies dispute resolution processes for subcontractors.
Any disputes arising between the contractor and subcontractor related to the performance of the work will be resolved in accordance with the dispute resolution procedures outlined in this Agreement. The contractor shall ensure that the subcontractor agrees to and follows these procedures.
Subcontracting clause for subcontractor’s insurance requirements
This clause mandates subcontractor insurance coverage.
The subcontractor must maintain adequate insurance coverage, including general liability, workers’ compensation, and any other insurance required by applicable law or the contractor. The subcontractor shall provide proof of insurance upon request and ensure that the insurance covers all work performed under this Agreement.
Subcontracting clause for subcontractor’s obligations on termination
This clause outlines the subcontractor’s obligations in the event of termination.
If the subcontractor’s engagement is terminated, whether by the contractor or by mutual agreement, the subcontractor shall cease all work and return any property belonging to the contractor or client. The subcontractor will be compensated for any work completed up to the termination date, subject to verification and approval by the contractor.
Subcontracting clause for subcontractor’s duties regarding confidentiality and non-disclosure
This clause ensures confidentiality by subcontractors.
The subcontractor agrees to maintain confidentiality regarding all proprietary information, business plans, and client data disclosed during the course of work under this Agreement. The subcontractor shall not disclose or use any confidential information for any purpose other than the performance of the work under this Agreement.
Subcontracting clause for subcontractor’s adherence to work schedule
This clause sets expectations for subcontractor timelines.
The subcontractor shall adhere to the project’s agreed-upon schedule. Any delay in the subcontractor’s performance of the work will be reported to the contractor immediately, and the subcontractor must take corrective action to prevent further delays. The contractor reserves the right to impose penalties for missed deadlines caused by the subcontractor’s actions.
Subcontractor clause for subcontractor’s provision of progress updates
This clause requires subcontractors to provide progress updates.
The subcontractor shall provide regular progress updates to the contractor at intervals agreed upon at the start of the project. These updates must include detailed reports on completed work, challenges faced, and any changes to the project schedule or scope of work.
Subcontractor clause for subcontractor’s responsibility for delays
This clause places responsibility for delays on the subcontractor.
The subcontractor shall be responsible for any delays caused by their actions or failures to perform under this Agreement. If delays occur, the subcontractor must work to resolve them at no additional cost to the contractor or client.
Subcontractor clause for subcontractor’s indemnity regarding damages
This clause ensures indemnity from the subcontractor for damages.
The subcontractor agrees to indemnify and hold harmless the contractor and client from any claims, damages, or losses arising from the subcontractor's negligence, actions, or failure to perform its obligations under this Agreement.
Subcontractor clause for subcontractor’s adherence to quality standards
This clause requires subcontractors to adhere to quality standards.
The subcontractor is required to perform all work to the highest industry standards and in accordance with the specifications outlined in this Agreement. The contractor will inspect the work periodically to ensure compliance with these quality standards.
Subcontractor clause for subcontractor’s provision of compliance certificates
This clause requires compliance certificates from the subcontractor.
The subcontractor shall provide the contractor with any necessary compliance certificates related to the work, including certifications for safety standards, environmental compliance, or industry-specific regulations.
Subcontractor clause for subcontractor’s maintenance of licenses
This clause requires subcontractors to maintain necessary licenses.
The subcontractor shall maintain all necessary licenses, permits, and certifications required for the performance of the work. The subcontractor will provide evidence of such licenses to the contractor upon request.
Subcontractor clause for subcontractor’s compliance with safety regulations
This clause mandates safety compliance by subcontractors.
The subcontractor must comply with all applicable safety regulations during the performance of the work. The subcontractor will ensure that all workers are properly trained and equipped to follow safety protocols on the job site.
Subcontractor clause for subcontractor’s responsibility for tools and equipment
This clause places responsibility for tools on the subcontractor.
The subcontractor shall be responsible for providing all necessary tools, equipment, and materials to perform the work. The subcontractor will ensure that all equipment used is in good working condition and meets safety standards.
Subcontractor clause for subcontractor’s adherence to work scope
This clause ensures subcontractors adhere to the work scope.
The subcontractor agrees to perform only the work specified in this Agreement and in accordance with the scope outlined. Any additional work must be approved in writing by the contractor before it is undertaken.
Subcontractor clause for subcontractor’s obligation to return property
This clause ensures subcontractors return company property.
Upon the completion or termination of the work, the subcontractor shall promptly return any property, tools, or materials belonging to the contractor or client. The subcontractor will bear the costs of replacing or repairing any damaged or lost property.
Subcontractor clause for subcontractor’s responsibility for warranty claims
This clause ensures subcontractor responsibility for warranty claims.
The subcontractor will be responsible for addressing any warranty claims related to the work performed under this Agreement. If any defects arise within the warranty period, the subcontractor must correct them at no cost to the contractor or client.
Subcontractor clause for subcontractor’s coordination with other subcontractors
This clause requires coordination with other subcontractors.
If multiple subcontractors are involved in the project, the subcontractor agrees to coordinate and cooperate with other subcontractors to ensure the smooth and efficient execution of the work. Any conflicts or overlaps in duties should be resolved with the contractor’s assistance.
Subcontractor clause for subcontractor’s responsibility for payment to sub-subcontractors
This clause defines responsibility for sub-subcontractor payments.
The subcontractor is responsible for paying any sub-subcontractors they engage to perform work. The contractor will not be liable for any payments owed to sub-subcontractors, and all payments will be handled directly by the subcontractor.
Subcontractor clause for subcontractor’s submission of invoices
This clause defines invoicing procedures for subcontractors.
The subcontractor will submit invoices for completed work in accordance with the payment schedule outlined in this Agreement. Each invoice must detail the work performed, materials used, and any other costs incurred in the execution of the work.
Subcontractor clause for subcontractor’s duty to follow change orders
This clause ensures compliance with change orders.
Any changes to the scope of work must be documented in a change order, which must be signed by both the contractor and subcontractor. The subcontractor agrees to adhere to any changes in work or costs as outlined in the change order.
Subcontractor clause for subcontractor’s obligation to handle disputes
This clause sets procedures for handling subcontractor disputes.
Any disputes arising between the contractor and subcontractor regarding performance or interpretation of this Agreement shall be resolved through the dispute resolution procedures outlined in this Agreement. The subcontractor agrees to cooperate in resolving any issues that may arise.
Subcontractor clause for subcontractor’s duty to meet delivery deadlines
This clause ensures subcontractors meet deadlines.
The subcontractor agrees to meet all delivery deadlines as specified in this Agreement. If the subcontractor anticipates a delay, they must notify the contractor immediately and work to mitigate the delay to avoid project disruptions.
Subcontractor clause for subcontractor’s responsibility for compliance with ethical standards
This clause mandates ethical conduct by subcontractors.
The subcontractor shall conduct business ethically and in accordance with all applicable laws and regulations. The subcontractor will not engage in any fraudulent, corrupt, or unethical behavior while performing work under this Agreement.
Subcontractor clause for subcontractor’s obligation to remedy defective work
This clause requires the subcontractor to remedy defects.
If any work performed by the subcontractor is found to be defective or below the quality standards outlined in this Agreement, the subcontractor will immediately remedy the defects at no cost to the contractor or client. If the subcontractor fails to do so, the contractor may take corrective action at the subcontractor's expense.
Subcontractor clause for subcontractor’s reporting of subcontracting issues
This clause requires subcontractors to report issues.
The subcontractor must promptly report any issues that could impact the quality, timeline, or cost of the work to the contractor. These reports should include detailed information about the problem, potential solutions, and any support required from the contractor or client.
Subcontractor clause for subcontractor’s confidentiality obligations
This clause ensures confidentiality by subcontractors.
The subcontractor agrees to keep all proprietary information and business data related to the project confidential. The subcontractor will not disclose any such information to third parties or use it for any purpose other than completing the work outlined in this Agreement.
Subcontractor clause for subcontractor’s obligation to provide documentation
This clause requires the subcontractor to provide documentation.
The subcontractor shall provide all necessary documentation, including work reports, progress photos, and invoices, to the contractor as required by the terms of this Agreement. All documents should be accurate, complete, and submitted in a timely manner for verification.
Subcontractor clause for subcontractor’s adherence to project specifications
This clause ensures subcontractors follow project specifications.
The subcontractor agrees to follow the project specifications and requirements outlined by the contractor. Any deviation from these specifications must be approved by the contractor in writing before proceeding with the work.
Subcontractor clause for subcontractor’s protection of client property
This clause ensures subcontractors protect client property.
The subcontractor is responsible for safeguarding all client property while performing the work under this Agreement. This includes ensuring that no damage occurs to the property and returning it in the same condition as it was received.
Subcontractor clause for subcontractor’s approval of change in work
This clause ensures that changes in work are approved.
The subcontractor shall not begin any work that deviates from the original scope without obtaining written approval from the contractor. Any approved changes to the work will be documented in a change order, which will specify the additional costs, if any.
Subcontractor clause for subcontractor’s notification of unforeseen circumstances
This clause requires subcontractors to notify of unforeseen circumstances.
The subcontractor agrees to notify the contractor immediately of any unforeseen circumstances or obstacles that may affect the performance of the work. This includes, but is not limited to, delays, supply shortages, or issues related to weather conditions.
Subcontractor clause for subcontractor’s responsibility for project completion
This clause ensures the subcontractor is responsible for completing the project.
The subcontractor agrees to complete all work specified in this Agreement within the timeline outlined. If any part of the work is incomplete or not up to standard, the subcontractor will be responsible for rectifying it promptly and at no additional cost to the contractor.
Subcontractor clause for subcontractor’s right to dispute payment
This clause allows the subcontractor to dispute payment.
If the subcontractor believes they have not been paid in accordance with this Agreement, they have the right to dispute the payment in writing within [insert time period]. The contractor will review the dispute and make a determination in accordance with the terms of the contract.
Subcontractor clause for subcontractor’s requirement to comply with industry standards
This clause ensures subcontractors comply with industry standards.
The subcontractor agrees to perform all work in compliance with industry standards and best practices. The subcontractor must meet or exceed the quality requirements specified in this Agreement and be able to demonstrate compliance upon request by the contractor.
Subcontractor clause for subcontractor’s obligation to secure permits
This clause requires subcontractors to secure necessary permits.
The subcontractor is responsible for obtaining any permits, licenses, or approvals necessary for the completion of the work under this Agreement. The subcontractor will ensure all work complies with relevant zoning laws, building codes, and other applicable regulations.
Subcontractor clause for subcontractor’s cooperation in audit
This clause ensures the subcontractor cooperates with audits.
The subcontractor agrees to cooperate fully with any audit or inspection by the contractor or client. The subcontractor will provide all relevant records, documents, and access to personnel as necessary for the audit process.
Subcontractor clause for subcontractor’s responsibility for subcontracting further
This clause limits the subcontractor's ability to further subcontract.
The subcontractor shall not further subcontract any part of the work under this Agreement without prior written approval from the contractor. Any unauthorized subcontracting will be deemed a breach of this Agreement.
Subcontractor clause for subcontractor’s communication with the contractor
This clause establishes communication expectations between the subcontractor and contractor.
The subcontractor agrees to maintain open communication with the contractor throughout the duration of the work. Any issues, delays, or changes to the project must be communicated in a timely manner to ensure the smooth progression of the work.
Subcontractor clause for subcontractor’s responsibility for site conditions
This clause holds the subcontractor accountable for site conditions.
The subcontractor is responsible for ensuring that the work site is properly prepared and safe for the work to be performed. Any existing site conditions that may impact the work must be reported to the contractor immediately for resolution.
Subcontractor clause for subcontractor’s agreement to follow safety protocols
This clause requires subcontractors to follow safety protocols.
The subcontractor agrees to adhere to all safety protocols outlined in this Agreement and any applicable safety regulations. The subcontractor is responsible for providing appropriate safety training and equipment to their employees, ensuring a safe working environment at all times.
Subcontractor clause for subcontractor’s responsibility for final inspection
This clause requires the subcontractor to ensure a final inspection is conducted.
Upon completion of the work, the subcontractor will notify the contractor to schedule a final inspection. The subcontractor is responsible for ensuring that the work meets the standards outlined in this Agreement and addressing any issues identified during the inspection.
Subcontractor clause for subcontractor’s non-disclosure of work-related details
This clause mandates confidentiality regarding work-related details.
The subcontractor agrees to keep all details related to the work, including the terms of this Agreement, confidential and will not disclose any proprietary information to third parties without the prior written consent of the contractor.
Subcontractor clause for subcontractor’s agreement to work in accordance with timelines
This clause ensures subcontractors meet deadlines.
The subcontractor agrees to complete the work within the timelines specified in this Agreement. Any delays must be communicated promptly to the contractor, and the subcontractor must take immediate steps to make up for any lost time.
Subcontractor clause for subcontractor’s responsibility for work quality
This clause makes the subcontractor responsible for work quality.
The subcontractor is responsible for ensuring that all work is performed to the highest quality standards, in accordance with the specifications outlined in this Agreement. The subcontractor must rectify any work that does not meet the specified standards at no additional cost to the contractor.
Subcontractor clause for subcontractor’s obligation to follow dispute resolution process
This clause requires the subcontractor to follow dispute resolution procedures.
Any disputes between the contractor and subcontractor arising under this Agreement must be resolved in accordance with the dispute resolution procedures outlined in this Agreement. The subcontractor agrees to participate in good faith in the resolution process.
Subcontractor clause for subcontractor’s responsibility for legal compliance
This clause ensures the subcontractor complies with legal requirements.
The subcontractor agrees to comply with all applicable legal requirements, including labor laws, tax regulations, and any other statutory obligations related to the work. The subcontractor will indemnify the contractor for any fines or penalties resulting from non-compliance.
Subcontractor clause for subcontractor’s obligation to handle claims
This clause sets the subcontractor's obligation for claims handling.
The subcontractor shall promptly handle any claims or complaints made by third parties in relation to the work performed. The subcontractor will notify the contractor immediately of any claims and take all necessary steps to resolve them efficiently.
Subcontractor clause for subcontractor’s agreement to follow terms and conditions
This clause ensures subcontractors follow the terms and conditions of the agreement.
The subcontractor agrees to adhere to all the terms and conditions specified in this Agreement. Any failure to follow the agreed-upon terms will be considered a breach of contract and may result in the termination of the subcontractor’s engagement.
Subcontractor clause for subcontractor’s obligation to obtain written approval for changes
This clause requires subcontractors to obtain written approval for any changes.
The subcontractor shall not make any changes to the work, including adjustments to the scope, timeline, or cost, without prior written approval from the contractor. Any unauthorized changes will be considered a breach of this Agreement.
Subcontractor clause for subcontractor’s agreement to provide necessary permits
This clause ensures subcontractors provide necessary permits.
The subcontractor is responsible for obtaining all necessary permits and licenses required for the performance of the work. This includes all local, state, and federal permits related to the tasks outlined in this Agreement.
Subcontractor clause for subcontractor’s duty to cooperate with the contractor
This clause emphasizes subcontractor cooperation with the contractor.
The subcontractor agrees to cooperate fully with the contractor to ensure the successful completion of the work. This includes assisting with any inquiries, providing necessary documentation, and supporting the contractor’s efforts to meet project milestones.
Subcontractor clause for subcontractor’s provision of work progress reports
This clause mandates subcontractors to provide work progress reports.
The subcontractor agrees to submit regular progress reports detailing the status of the work, any delays, and updates on key milestones. These reports shall be submitted on a [insert frequency] basis and should include any issues requiring the contractor’s attention.
Subcontractor clause for subcontractor’s responsibility for materials and supplies
This clause makes the subcontractor responsible for materials and supplies.
The subcontractor is responsible for providing all materials and supplies required to complete the work. The subcontractor will ensure that all materials meet the specified quality standards and are delivered on time to avoid delays in the project.
Subcontractor clause for subcontractor’s warranty of work
This clause ensures the subcontractor provides a warranty for the work.
The subcontractor warrants that the work performed under this Agreement will be free from defects for a period of [insert duration]. If defects are discovered during the warranty period, the subcontractor shall correct them at no additional cost to the contractor or client.
Subcontractor clause for subcontractor’s responsibility for non-performance
This clause places responsibility for non-performance on the subcontractor.
In the event the subcontractor fails to perform any part of the work as specified in this Agreement, the subcontractor will be responsible for rectifying the non-performance at its own cost. The contractor reserves the right to take corrective action and charge the subcontractor for any costs incurred due to non-performance.
Subcontractor clause for subcontractor’s duty to maintain proper insurance
This clause ensures the subcontractor maintains proper insurance.
The subcontractor shall maintain adequate insurance coverage, including general liability insurance and workers' compensation, for the duration of the project. The contractor reserves the right to request proof of such insurance at any time during the contract term.
Subcontractor clause for subcontractor’s provision of a performance bond
This clause requires the subcontractor to provide a performance bond.
The subcontractor must provide a performance bond in the amount of [insert amount] to guarantee the completion of the work in accordance with this Agreement. The bond must be submitted before work commences and will be held until the completion of the project.
Subcontractor clause for subcontractor’s obligation to rectify errors
This clause mandates the subcontractor rectify errors.
The subcontractor is responsible for correcting any errors or omissions in the work at no cost to the contractor. If the subcontractor fails to correct any defects within a reasonable time frame, the contractor may engage another party to correct the issue at the subcontractor’s expense.
Subcontractor clause for subcontractor’s obligation to meet deadlines
This clause ensures subcontractors meet deadlines.
The subcontractor agrees to complete the work within the agreed deadlines as outlined in this Agreement. If the subcontractor fails to meet these deadlines, they will be responsible for any associated costs or delays resulting from the missed deadlines.
Subcontractor clause for subcontractor’s provision of all necessary documentation
This clause ensures the subcontractor provides necessary documentation.
The subcontractor shall provide all required documentation, including work logs, receipts, and invoices, to the contractor for review and record-keeping. This documentation must be submitted in a timely manner and be complete and accurate.
Subcontractor clause for subcontractor’s compliance with project changes
This clause requires the subcontractor to comply with project changes.
Any changes to the scope, timeline, or cost of the work must be formally approved by the contractor in writing. The subcontractor agrees to comply with these changes and adjust their work accordingly, as outlined in any change orders issued under this Agreement.
Subcontractor clause for subcontractor’s compliance with the contractor’s directions
This clause ensures the subcontractor follows the contractor’s directions.
The subcontractor agrees to follow all directions and instructions issued by the contractor during the performance of the work. Any deviation from these instructions without the contractor’s prior approval will be considered a breach of this Agreement.
Subcontractor clause for subcontractor’s obligation to adhere to legal requirements
This clause ensures the subcontractor adheres to legal requirements.
The subcontractor shall comply with all applicable local, state, and federal laws, including labor, safety, environmental, and tax laws, in the performance of the work. The subcontractor is responsible for obtaining all necessary permits and licenses required for the project.
Subcontractor clause for subcontractor’s responsibility for non-disclosure of sensitive information
This clause requires the subcontractor to keep sensitive information confidential.
The subcontractor agrees not to disclose any sensitive information obtained during the performance of the work under this Agreement. This includes business plans, financial data, and any other proprietary information. The subcontractor will not use such information for personal or third-party gain.
Subcontractor clause for subcontractor’s rights upon project termination
This clause addresses the subcontractor’s rights upon termination.
If this Agreement is terminated for any reason, the subcontractor is entitled to payment for work completed up to the termination date, provided the work meets the standards outlined in this Agreement. The subcontractor must return any client property and cease all work immediately upon termination.
Subcontractor clause for subcontractor’s compliance with dispute resolution
This clause sets a dispute resolution process for the subcontractor.
Any disputes arising under this Agreement shall be resolved in accordance with the dispute resolution procedures outlined in the Agreement. The subcontractor agrees to participate in the resolution process, including mediation or arbitration if necessary, to settle any disagreements.
Subcontractor clause for subcontractor’s obligation to maintain documentation
This clause requires subcontractors to maintain and provide documentation.
The subcontractor agrees to maintain detailed records of the work performed, including time logs, materials used, and any correspondence with the contractor. These records will be made available to the contractor upon request for verification and auditing purposes.
Subcontractor clause for subcontractor’s responsibility for errors and omissions
This clause addresses the subcontractor’s responsibility for errors.
The subcontractor is responsible for the correction of any errors or omissions in the work performed. If the subcontractor’s work is found to be deficient or not in compliance with the agreed-upon standards, the subcontractor shall correct the work at no additional cost to the contractor or client.
Subcontractor clause for subcontractor’s obligations in the event of subcontractor's default
This clause outlines the subcontractor's obligations in case of default.
In the event that the subcontractor defaults on any of its obligations, the subcontractor will immediately notify the contractor and take necessary actions to remedy the situation. If the default is not rectified within [insert period], the contractor reserves the right to terminate the subcontractor’s engagement and seek another provider to complete the work.
Subcontractor clause for subcontractor’s agreement to follow contractor’s instructions
This clause requires the subcontractor to follow instructions.
The subcontractor agrees to follow all reasonable instructions given by the contractor. Any deviation from these instructions without prior written approval from the contractor will be considered a breach of contract.
Subcontractor clause for subcontractor’s ability to subcontract further
This clause limits the subcontractor’s ability to further subcontract.
The subcontractor shall not subcontract any part of the work without the prior written consent of the contractor. If approved, the subcontractor shall ensure that any further subcontracting complies with all terms and conditions of this Agreement.
Subcontractor clause for subcontractor’s compliance with local regulations
This clause requires subcontractors to comply with local laws.
The subcontractor shall comply with all relevant local, state, and federal laws and regulations during the performance of work under this Agreement. This includes obtaining any necessary permits, paying required fees, and adhering to safety and environmental standards.
Subcontractor clause for subcontractor’s responsibilities regarding work stoppages
This clause defines the subcontractor’s responsibility for work stoppages.
The subcontractor is responsible for immediately notifying the contractor of any circumstances that could cause a work stoppage. If a stoppage is due to the subcontractor’s actions or failure to perform, the subcontractor will bear the costs associated with the delay.
Subcontractor clause for subcontractor’s right to inspect the work site
This clause grants the subcontractor the right to inspect the work site.
The subcontractor is entitled to inspect the work site before commencing work to ensure that all conditions are suitable for the performance of the work. The subcontractor must report any concerns about site conditions to the contractor before starting work.
Subcontractor clause for subcontractor’s performance bond requirement
This clause requires the subcontractor to provide a performance bond.
The subcontractor must provide a performance bond in the amount of [insert amount] to guarantee the completion of the work. The bond will be held by the contractor until the work is completed to the contractor’s satisfaction.
Subcontractor clause for subcontractor’s insurance coverage requirement
This clause ensures that the subcontractor maintains insurance coverage.
The subcontractor is required to maintain comprehensive insurance coverage, including general liability and workers’ compensation, to cover any risks associated with the performance of the work. Proof of insurance must be provided to the contractor before work commences.
Subcontractor clause for subcontractor’s obligations regarding the use of client property
This clause specifies the subcontractor’s obligations regarding client property.
The subcontractor agrees to use the client’s property only for the purposes of performing the work under this Agreement. The subcontractor is responsible for maintaining the property in good condition and must return any client property upon completion of the work.
Subcontractor clause for subcontractor’s duty to cooperate with other subcontractors
This clause emphasizes cooperation among subcontractors.
The subcontractor agrees to cooperate with other subcontractors engaged by the contractor to ensure the timely and efficient completion of the work. The subcontractor will coordinate with other parties to prevent conflicts and ensure that all work is completed on schedule.
Subcontractor clause for subcontractor’s right to dispute non-payment
This clause allows subcontractors to dispute non-payment.
If the subcontractor believes payment has been incorrectly withheld, they have the right to dispute the non-payment in writing within [insert time period]. The contractor will review the dispute and make any necessary adjustments to the payment.
Subcontractor clause for subcontractor’s obligation to comply with environmental standards
This clause requires subcontractors to comply with environmental regulations.
The subcontractor agrees to adhere to all environmental standards and regulations during the performance of the work. The subcontractor will ensure that any materials used are environmentally friendly, and all waste is disposed of properly according to legal requirements.
Subcontractor clause for subcontractor’s responsibility for work delays
This clause ensures the subcontractor is responsible for delays.
If the subcontractor causes any delays in the completion of the work, they will be liable for any additional costs incurred by the contractor or client due to the delay. The subcontractor must notify the contractor promptly of any potential delays to allow for corrective measures.
Subcontractor clause for subcontractor’s compliance with quality control procedures
This clause ensures compliance with quality control.
The subcontractor agrees to comply with the contractor’s quality control procedures. The subcontractor is responsible for ensuring that all work meets the quality standards specified in this Agreement, and must make any necessary adjustments to ensure compliance.
Subcontractor clause for subcontractor’s right to terminate for non-performance
This clause gives the subcontractor the right to terminate for non-performance.
The subcontractor has the right to terminate the Agreement if the contractor fails to fulfill their obligations, including failing to make timely payments or provide necessary support for the completion of the work. The subcontractor must provide written notice of termination to the contractor before ending the Agreement.
Subcontractor clause for subcontractor’s obligations in case of project cancellation
This clause addresses subcontractor obligations in case of cancellation.
If the project is canceled or suspended before completion, the subcontractor will be compensated for the work completed up to the date of cancellation. The subcontractor agrees to return any materials, tools, or equipment provided by the contractor upon cancellation.
Subcontractor clause for subcontractor’s obligations in the event of legal claims
This clause ensures subcontractor accountability for legal claims.
The subcontractor will indemnify the contractor against any legal claims arising from the subcontractor’s performance of the work. The subcontractor shall bear the cost of defending against such claims and shall pay any damages or settlements related to such claims.
Subcontractor clause for subcontractor’s responsibility for obtaining necessary licenses
This clause ensures that the subcontractor obtains necessary licenses.
The subcontractor is responsible for obtaining any necessary licenses, permits, or certifications required for the performance of work under this Agreement. The subcontractor shall provide the contractor with proof of such licenses prior to the commencement of work.
Subcontractor clause for subcontractor’s compliance with labor standards
This clause ensures the subcontractor complies with labor standards.
The subcontractor agrees to comply with all applicable labor laws, including wage and hour laws, worker’s compensation, and anti-discrimination provisions. The subcontractor will be solely responsible for any claims arising from labor law violations during the performance of the work.
This article contains general legal information and does not contain legal advice. Cobrief is not a law firm or a substitute for an attorney or law firm. The law is complex and changes often. For legal advice, please ask a lawyer.